UncategorizedPandemic Legal intelligence Infrastructure & Energy Projects

June 22, 20200
Impact on Infrastructure
1. What is the impact of the pandemic Covid-19 and the 21 day lockdown on the Infrastructure Sector in India?
Answer: Due to the pandemic Covid-19, the Infrastructure Sector and the projects have been stopped until further orders and have been on a standstill in lieu of the directions of the Central Government for a nationwide lockdown till 15.04.2020 vide Ministry of Home Affairs’ notification no. 40-3/2020-DM-I(A) dated 24.03.2020.
In the same notification, the Government has specified certain essential services which would be allowed to continue.
Rest everything, including all infrastructure projects, were ordered to be stopped until further orders.
Ongoing Infrastructure & Energy Projects
2. What will happen to the ongoing Infrastructure projects such as EPC Projects, Energy Sector Projects, Turnkey Projects, Highway projects, etc.?
Answer: Owing to the Notification by the Government dated 24.03.2020, every infrastructure project has been put on hold until further orders.
However, an exception to this are the Renewable Energy Generation Stations (REGS) including Solar Power Plants, Wind Power Plants, Solar-Wind Hybrid Power Plants, etc. which requested the Government to consider them as an “Essential Service” vide D.O. No. 283/18/2020-GRID SOLAR dated 26.03.2020 by the Ministry of New & Renewable Energy (MNRE).
This would mean that all these stations and projects would be exempt from the conditions of lockdown and would be allowed to function smoothly albeit being in compliance with the social distancing and sanitary norms issued by the Government from time to time.
These RE Projects have also been given relief in receiving payments from state DISCOMs, i.e., the DISCOMs have been directed to make regular payments to them as was being before lockdown.
This clarification was issued vide MNRE Office Memorandum no. 283/20/2020 – GRID SOLAR(ii) dated 01.04.2020.
One needs to have detailed legal analysis regarding the Renewable Energy (RE) Projects allowed by the Government under the lockdown period.
Effect on Supply Chain
3. Is there any effect on the supply chain or the workforce because of the lockdown in view of the pandemic Covid-19?
Answer: There have been massive supply chain disruptions for the projects and the workforce has also been affected due to the COVID – 19 pandemic. All over the country, only essential commodities are allowed to be supplied.
Keeping this situation in mind, the Ministry of New & Renewable Energy through a Press Release dated 26.3.2020 has provided an extension of time to the Renewable Projects citing reasons of slow or no supply of necessary goods and services and the lack of workforce.
However, the risk assessments and implications of stoppage of such infrastructure projects requires a meticulous deliberation.
EPC Projects and Contracts
4. How does the current pandemic situation affect the obligations of the EPC contractors who have entered into separate agreements with the contractors, vendors, sub- contractors, sub-vendors and so on?
(Sub questions:
a. Does your Contract provide for a situation like this?
b. Does your contract qualify the current scenario as a Force Majeure situation?
c. Would there be any penalties or financial obligations due to lockdown and operations coming to a grinding halt or at sub-optimal level in the current scenario?)
Answer: The language as used in most contracts varies and, therefore, it is important to review each contract and its corollary of documents holistically and carefully before initiating any actions /decisions.
It is important to refer the Force Majeure, Termination, Notice, Dispute Resolution Clauses as well as the rights and obligations mentioned in the contracts for each party.
Speak to legal experts to get a detailed analysis of the legal obligations specifically pertaining to your EPC Contract as well as the supplementary contracts there under with separate vendors, contractors, sub-contractors, etc.
5. Does the termination of an EPC Contract lead to an automatic termination of all associated contracts therewith? If not, how can I protect my company’s interest in such a scenario?
Answer: Generally termination of EPC contracts does not auto-terminate its secondary or associated contracts, unless agreed to the contrary.
More importantly, a termination Notice is required to be served towards the specific days which will depend on the contractual terms between the parties. The wording of the Force Majeure clause will also play an important role in the overall strategy.
In the interest of business and to protect the parties’ interests, the contracts, its terms and ancillary documents need proper techno-legal review to understand potential impact in this current scenario.
Force Majeure Clause
6. Can parties involved in Infrastructure projects or Energy Projects take the defense of Force Majeure?
Answer: Due to the major outbreak of Covid-19 in China, certain measures were taken by the Government of India to ensure the safety of its citizens and the individuals involved in different sectors.
In view of the same, the Department of Expenditure, Ministry of Finance, through Office Memorandum No. F. 18/4/2020-PPD dated 19.02.2020 declared Covid-19 as a Natural Calamity and notified that Force Majeure Clause can be invoked in the Government’s purchase contracts.
However, the invocation of Force Majeure clause solely depends on the terms and conditions of the contracts between the parties.
In cases where the contract between the parties does not have a Force Majeure Clause, there can still be a remedy available to the aggrieved party in terms of the legal provisions as contained under the Indian Contract Act, 1872.
The Ministry of New and Renewable Energy (MNRE) has also issued an Office Memorandum No. 283/18/2020-GRID SOLAR dated 20.03.2020 to give extension in the commissioning of the RE Projects due to the effect on various factors because of the Pandemic Covid 19 and considering it as a Force Majeure Event.
It is advised to take a well informed decision pertaining to contracts where Force Majeure Clause is not available to be invoked in the Infrastructure Projects and also if there are any limitations on the invocation of the Force Majeure Clause.
Force Majeure Clause
7. Is the COVID19 Pandemic scenario a Force Majeure situation for contractual obligations? If yes, does the ongoing COVID19 scenario suo-motu invoke the Force Majeure Clause in a contract or do I have to pro-actively invoke the said clause?
Answer: The current scenario has exposed the stakeholders of the economy to an unprecedented situation wherein it is impossible to provide a straight-jacket formula for determining the enforcement of obligations under varied contracts.
Usually, the invocation of a Force Majeure situation requires a pro-active notification process, however this may not be applicable to all contracts since every contract is unique to itself.
Recognising the force majeure event, invoking it timely and taking corrective or damage control decisions can change the fate of business for many coming years.
Force Majeure Clause
8. Can a Force Majeure notice be sent via email? Can it be mentioned in the body of the email or has to be invoked in a duly signed attachment to the email?
Answer: A contract may or may not have a clause determining the procedure for sending a notice under the contract, by either party.
Hence, whether or not an email can be considered as a valid notice to invoke Force Majeure depends on the specifications in the contract itself.
In case such a procedure is not mentioned in the contract, invoking it in the body of the email or as a separate attachment, both would work.
9. What If the contract does not have a force majeure clause?
Answer: Non-existence of a Force Majeure contract does not and cannot render an aggrieved party remediless in a peculiar situation such as the current pandemic.
Certain measures at the right time and in correct manner may be resorted to by the aggrieved parties to safeguard their interest.
However, that will also vary from contract to contract and no straight jacket formula can be provided without intricate study of the specific contract.
Force Majeure Clause
10. Can A Force Majeure Clause Be Implied Under The Contract?
Answer: A force majeure clause cannot be implied under Indian law. It must be expressly provided for under the contract and protection afforded will depend on the language of the clause.
In the event of a dispute as to the scope of the clause, the Courts are likely to apply the usual principles of contractual interpretation.
11. Who Has The Burden Of Proof To Establish A Force Majeure Event?
Answer: As a general practice, the party that has been unable to perform the contract due to Force Majeure has the onus to prove it.
However, it may vary in exceptional circumstances.
A proactive due diligence is advisable in building a checklist and repository of all supporting evidence to discharge this burden of proof.
Tenders in Projects
12. How would the current scenario affect the tenders acquired by businesses? Will the legal obligations to provide the goods and/or services under the tender suo-motu be brought to a halt or the concerned parties shall have to pro-actively notify each other or take steps to minimize and/or avoid financial losses or in some cases, terminate the tender contract?
Answer: All the tenders and contracts (except for those dealing in essential commodities subject to renewed conditions if any) would come to suo-motu halt in the current circumstances. The verbiage used in the Force Majeure and the Termination Clause would be very important to determine the impact, rights, obligations, and liabilities of the respective parties.
It is strongly advised to put in writing and communicate properly the invocation of the Force Majeure clause or the termination of the contract by following the process as enshrined under those respective clauses.
However, for opinion on specific queries regarding your contract, please get in touch with a legal expert to avoid unforeseen liabilities.
Impact on Toll Booths
13. What would be the impact of the current Pandemic situation on Toll Booths and Toll Collection?
Answer: The Road Transport and Highways Ministry has directed the National Highways Authority of India (NHAI) to suspend toll collections across the country during the lockdown period of 21 days till 14th April.
For concessions given to the Toll Booth operators, the period of the concession would be extended by a period equal in length to the period during which the Concessionaire is unable to collect tolls.
Maintenance of roads and availability of emergency services at toll plazas have asked to be continued to have a proactive approach in any emergency situation.
Relaxations/Waivers
14. Are there any circulars/notifications pertaining to the relaxation or the waiver of terms and conditions with regard to payback of loans and interest thereon to banks and financial institutions?
What would happen to Performance Bank Guarantees and the interest thereon?
Answer: Recently, RBI has in its notification DOR.No.BP.BC.47/21.04.048/2019-20 on March 27, 2020 addressed certain regulatory measures that were announced to mitigate the burden of debt servicing brought about by disruptions on account of COVID-19 pandemic.
There is nothing specific on Performance Bank Guarantee known till the date of release of this white paper.
Dispute Resolution Clause
15. What would happen to the dispute resolution clause of the Contract in the current contract?
Can the Force Majeure event be a matter of dispute to be adjudicated under the Dispute Resolution Clause?
Answer: Key contracts should be analysed to assess the parties’ rights and obligations, including with respect to termination, force majeure, governing law and dispute resolution.
If the Force Majeure clause of the contract is subject to interpretation, it can be brought under the ambit of dispute resolution clause to reach the right conclusion.
We at AMLEGALS anticipate that the disputes which will crop up in this pandemic business cycle will be different than dispute arising during normal business cycle. Hence, very cautious approach is needed and any negligent approach can be suicidal for business.
Wages/Salary
16. Whether Companies are allowed to deduct salaries of their workers working in these infrastructure projects?
Answer: The Ministry of Home Affairs vide Order no. 40-3/2020-DM-I(A) dated 29.03.2020 has directed all the employers, be it in the industry or in the shops and commercial establishments, to make payment of wages of their workers, on the due date at their work places, without any deductions, for the period of lockdown of establishments. The mandatory direction stands withdrawn from 18th May, 2020.
The Government has also declared many reliefs for such labours’ working on these projects.
Relaxations – Ministry of New & Renewable Energy
17. Are there any relaxations given by Ministry of New and Renewable Energy with respect to the implementation of Approved Lists of Models and manufacturing of Solar PV modules and cells?
Answer: Yes, the Ministry of New and Renewable Energy have provided relaxations by extending the dates of the implementation of Approved Lists of Models & Manufacturers for Solar PV modules and cells (ALMM) vide Press Release dated 21.04.2020.
Due to the prevalent situation of the pandemic, it has been decided to extend the date from 31.03.2020 to 30.09.2020. The order pertaining to ALMM mentions that the all the Solar PV Power Projects shall be bidding out as per the Central government’s bidding guidelines.
18. What decision has been taken by the Ministry of New & Renewable Energy (MNRE) with respect to the Foreign Direct investment Cell (FDI)?
Answer: After reviewing the current Foreign Direct Investment for curbing the takeover sand acquisitions of the Indian Companies due to the prevalent pandemic situation in the country.
The Government has decided to create the FDI cell in order to process the FDI proposals with the Ministry of New & Renewable Energy vide Order No. F. No. 149/3/2020-P and C dated 08.06.2020.
Relaxations – Ministry of Aviation
19. Are there any extensions provided pertaining to the validity of initial NOC for Scheduled/ Scheduled Commuter/ Non-Scheduled Air Transport Services?
Answer: Although the guidelines issued on 22nd January, 2020 by the Ministry were very clear on the validity of initial NOC for Scheduled/ Scheduled Commuter/ Non-Scheduled Air Transport Services which was 3 years with no extension.
However, owing to the pandemic situation, a decision has been taken to extend the validity of initial NOC for Scheduled/ Scheduled Commuter/ Non-Scheduled Air Transport Services expiring between 1st March, 2020 and 31st August, 2020 till 31st December, 2020.
Extension in Motor Vehicles Act, 1988
20. Are there any extensions provided under the Motor Vehicles Act, 1988 and Central Motor Vehicle Rules, 1989 with respect to the validity of documents?
Answer: Owing to the complete lockdown imposed by the spread of COVID-19, on 30th March, 2020 the Ministry of Road Transport and Highways had issued an advisory to all the States and Union Territories with respect to the extension of validity of the documents related to Motor Vehicles Act, 1988 and Central Motor Vehicle Rules, 1989.
The advisory stated that the validity of Fitness, Permit (all types), Driving License, Registration or any other concerned document(s) which had expired since 1st February, 2020 or would expire by 30th June 2020 and whose extension of validity could not or not likely be granted due to the lockdown, such document(s) may be treated to be valid till 30th June, 2020.
Further, considering the grim situation still continuing the advisory extended the date and the documents which had expired since 1st February, 2020 or would expire by 30th September, 2020, the same may be treated to be valid till 30th September, 2020.
21. Are there any relaxation provided under the Motor Vehicles Act, 1988 and Central Motor Vehicle Rules, 1989 with respect to permit fees/ taxes etc.?
Answer: The Ministry of Road Transport and Highways has issued a notification dated 21st May, 2020 providing that the fees paid on or after 1st February, 2020 for the activity(s) under Rule 32 or Rule 81 of the Central Motor Vehicle Rules, 1989, including renewal and if such activity(s) is not completed due to the prevention to be taken for current pandemic condition, the fees paid shall continue to remain valid. And no additional fees will be charged for any delay in paying the fees from 1st February, 2020 till 31st July, 2020.
The State and Union Territories are also advised to consider provisions for relaxation in requirement of permit, or fees or taxes for renewal/ penalty for permits etc. under the Motor Vehicles Act, 1988 and were requested to consider the following provisions provided under the Motor Vehicles Act, 1988:
Subsections 3(f) and 3(n) of Section 66– which provides exemption from requirement of permit to transport vehicle by State Government.
Clause (viii) of sub-section 2 of section 96- which provides for exemption of prescribed person or prescribed classes of persons from payment of all or any or any portion of the fees payable under Chapter V of the Motor Vehicles Act, 1988.
Section 211 which provides an exemption for any class of persons from the payment of fee in part or in full.
ABOUT US
AMLEGALS is a multi-specialised law firm. We would love to hear your views, queries, feedback and comments on anand@amlegals.com or rohit.lalwani@amlegals.com.

Leave a Reply

Your email address will not be published. Required fields are marked *

Current day month ye@r *

© 2020-21 AMLEGALS Law Firm in Ahmedabad, Mumbai, Kolkata, New Delhi, Bengaluru for IBC, GST, Arbitration, Contract, Due Diligence, Corporate Laws, IPR, White Collar Crime, Litigation & Startup Advisory, Legal Advisory.

 

Disclaimer & Confirmation As per the rules of the Bar Council of India, law firms are not permitted to solicit work and advertise. By clicking on the “I AGREE” button below, user acknowledges the following:
    • there has been no advertisements, personal communication, solicitation, invitation or inducement of any sort whatsoever from us or any of our members to solicit any work through this website;
    • user wishes to gain more information about AMLEGALS and its attorneys for his/her own information and use;
  • the information about us is provided to the user on his/her specific request and any information obtained or materials downloaded from this website is completely at their own volition and any transmission, receipt or use of this site does not create any lawyer-client relationship; and that
  • We are not responsible for any reliance that a user places on such information and shall not be liable for any loss or damage caused due to any inaccuracy in or exclusion of any information, or its interpretation thereof.
However, the user is advised to confirm the veracity of the same from independent and expert sources.